ÀÖÌìÌÃappÏÂÔØ

Prior To Final Payment Sample Clauses

POPULAR SAMPLE Copied 1 times
Prior To Final Payment.ÌýPrior to Final Payment, Claims by either the Owner or Design-Builder must be initiated by written notice to the other party within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later.
Source 1Source 2Source 3See All (30)
Prior To Final Payment.ÌýIf you cancel your holiday at any time you will forfeit your deposit and may also forfeit deposits paid to third parties.
Source 1
Prior To Final Payment.ÌýPrior to Final Payment, Claims by Contractor must be initiated by written notice to the Owner (1) within 21 days after occurrence of the event giving rise to such Claim or (2) within 21 days after the Contractor first recognizes or, in the exercise of reasonable care, should have first recognized the condition giving rise to the Claim, whichever of (1) or (2) occurs later. Failure of the Contractor to deliver notice of a Claim within the time period required by this Section shall result in a waiver of the Claim and all rights and remedies arising from the Claim.
Source 1Source 2
Prior To Final Payment.ÌýPrior to Final Payment, Claims by the Design-Builder for an increase in the Contract Sum or the Contract Time must be made within five (5) days after occurrence of the event giving rise to such Claim.
Source 1
Prior To Final Payment.ÌýClaims by either the Owner or the Design-Builder must be initiated by written notice to the other party. The Design-Builder waives all Claims and causes of action not commenced in accordance with this Section 14.1.2.
Source 1
Prior To Final Payment.ÌýPrior to Final Payment, Claims by either the Owner or Xxxxxxx must be initiated by written notice to the other party within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. This clause shall not be construed in any as a restriction on the time limit within which a party may assert rights in court or any arbitration.
Source 1
Prior To Final Payment.ÌýPrior to Final Payment, Claims by either the Owner or Desi initiated by written notice to the other party within 21 days after occurrence of the event givin within 21 days after the claimant first recognizes the condition giving rise to the Claim, whic
Source 1

Related to Prior To Final Payment

  • Final Payment A. Upon final completion and acceptance of the Work in accordance with Paragraph 15.06 of the General Conditions, Owner shall pay the remainder of the Contract Price as recommended by Engineer as provided in said Paragraph 15.06.

  • FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such 9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees. 9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from: (a) unsettled liens, (b) faulty or defective Work appearing after Substantial Completion, (c) failure of the Work to comply with the requirements of the Contract Documents, or (d) terms of any special warranties required by the Contract Documents. 9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.

  • Certain Additional Payments In connection with any assignment of rights and obligations of any Defaulting Lender hereunder, no such assignment shall be effective unless and until, in addition to the other conditions thereto set forth herein, the parties to the assignment shall make such additional payments to the Administrative Agent in an aggregate amount sufficient, upon distribution thereof as appropriate (which may be outright payment, purchases by the assignee of participations or subparticipations, or other compensating actions, including funding, with the consent of the Borrower and the Administrative Agent, the applicable pro rata share of Loans previously requested but not funded by the Defaulting Lender, to each of which the applicable assignee and assignor hereby irrevocably consent), to (x) pay and satisfy in full all payment liabilities then owed by such Defaulting Lender to the Administrative Agent, the L/C Issuer or any Lender hereunder (and interest accrued thereon) and (y) acquire (and fund as appropriate) its full pro rata share of all Loans and participations in Letters of Credit and Swing Line Loans in accordance with its Applicable Percentage. Notwithstanding the foregoing, in the event that any assignment of rights and obligations of any Defaulting Lender hereunder shall become effective under applicable Law without compliance with the provisions of this paragraph, then the assignee of such interest shall be deemed to be a Defaulting Lender for all purposes of this Agreement until such compliance occurs. Subject to acceptance and recording thereof by the Administrative Agent pursuant to subsection (c) of this Section, from and after the effective date specified in each Assignment and Assumption, the assignee thereunder shall be a party to this Agreement and, to the extent of the interest assigned by such Assignment and Assumption, have the rights and obligations of a Lender under this Agreement, and the assigning Lender thereunder shall, to the extent of the interest assigned by such Assignment and Assumption, be released from its obligations under this Agreement (and, in the case of an Assignment and Assumption covering all of the assigning Lender’s rights and obligations under this Agreement, such Lender shall cease to be a party hereto but shall continue to be entitled to the benefits of Sections 3.01, 3.04, 3.05 and 11.04 with respect to facts and circumstances occurring prior to the effective date of such assignment); provided, that except to the extent otherwise expressly agreed by the affected parties, no assignment by a Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender. Upon request, the Borrower (at its expense) shall execute and deliver a Note to the assignee Lender. Any assignment or transfer by a Lender of rights or obligations under this Agreement that does not comply with this subsection shall be treated for purposes of this Agreement as a sale by such Lender of a participation in such rights and obligations in accordance with subsection (d) of this Section.